HomeMy WebLinkAbout13379RESOLUTION NO. 13379
A RESOLUTION RESCINDING RESOLUTION NO. 13084
AND AWARDING A MATERIALS TESTING & INSPECTION
CONTRACT IN THE AMOUNT OF $99,800 TO
KLEINFELDER, INC. AND SETTING FORTH $10,000 FOR
CONTINGENCIES AND ADDITIONAL WORK FOR
PROJECT NO. 13-084 DILLON / I-25 INTERCHANGE
MATERIALS TESTING & INSPECTION SERVICES, AND
AUTHORIZING THE PURCHASING AGENT TO EXECUTE
THE SAME
WHEREAS, City Council previously awarded a Materials Testing & Inspection
Contract to Terracon Consultants, Inc. which the Project Management team is
recommending be terminated; and
WHEREAS, the proposal of Kleinfelder, Inc., of Pueblo, Colorado was the most
qualified of the remaining consultants based upon a Qualifications Based Selection lowest
of those bids determined to be responsible; NOW, THEREFORE,
BE IT RESOLVED BY THE CITY COUNCIL OF PUEBLO, that:
SECTION 1
Resolution Number 13084 (Awarding a Materials Testing & Inspection Contract to
Terracon Consultants, Inc.) is hereby rescinded. Payment for services to Terracon
Consultants, Inc. preceding this Resolution and henceforth shall be in accordance with
the terms of the Agreement.
SECTION 2.
A Contract for PROJECT NO. 13-084 Dillon/I-25 Interchange Materials Testing &
Inspection is hereby awarded to Kleinfelder, Inc. in the amount of $99,800. In addition to
the amount of the proposal set forth, as aforementioned, an additional amount as
stipulated in this section is hereby established for contingencies and additional work.
Contingencies and Additional Work . . . . $10,000
SECTION 3.
Funds for said project shall be from Project Code DT0801 – Dillon/I-25 Interchange
SECTION 4.
The Purchasing Agent is hereby authorized to execute said contract on behalf of
Pueblo, a Municipal Corporation, and the City Clerk shall affix the seal of the City thereto
and attest the same.
SECTION 5.
The officers and staff of the City are directed and authorized to perform any and
all acts consistent with the intent of this Resolution and the attached contract/agreement
to effectuate the transactions described therein.
SECTION 6.
This Resolution shall become effective immediately upon passage and approval.
INTRODUCED February 8, 2016
BY: Ed Brown
City Clerk’s Office Item # M-1
Background Paper for Proposed
Resolution
COUNCIL MEETING DATE: February 8, 2016
TO: President Stephen G. Nawrocki, and Members of City Council
CC: Sam Azad, City Manager
VIA: Gina Dutcher, City Clerk
FROM: Earl Wilkinson, Director of Public Works
SUBJECT: A RESOLUTION RESCINDING RESOLUTION NO. 13084 AND
AWARDING A MATERIALS TESTING & INSPECTION CONTRACT IN
THE AMOUNT OF $99,800 TO KLEINFELDER, INC. AND SETTING
FORTH $10,000 FOR CONTINGENCIES AND ADDITIONAL WORK FOR
PROJECT NO. 13-084 DILLON / I-25 INTERCHANGE MATERIALS
TESTING & INSPECTION SERVICES, AND AUTHORIZING THE
PURCHASING AGENT TO EXECUTE THE SAME
SUMMARY:
Attached is the Proposal for Materials Testing and Inspection from Kleinfelder, Inc. for the
remainder of the Dillon Interchange construction project.
PREVIOUS COUNCIL ACTION:
On October 14, 2014 City Council passed and approved Resolution No. 13084 which
awarded a Materials Testing & Inspection contract to Terracon, Inc. for Project No. 13-
084 Dillon Interchange Materials Testing & Inspection Services.
BACKGROUND:
This project will consist of Materials Inspection & Inspection during the remainder of the
construction for the Dillon Interchange project. A similar contract was awarded to
Terrracon Consultants, Inc. on October 14, 2014; however, the Construction
Management team decided that it would be in the best interest for the project if that
Contract was terminated and awarded to another Consultant.
The selection of Kleinfelder was based upon the Qualification Based Selection process
used previously for the initial award.
FINANCIAL IMPLICATIONS:
Funds for the Project will be paid out of DT0801 – Dillon Interchange.
BOARD/COMMISSION RECOMMENDATION:
None.
STAKEHOLDER PROCESS:
None.
ALTERNATIVES:
The continuation of Terracon’s contract might result in difficulties in closing out the
Contract (IGA) with CDOT and might affect reimbursement for the Dillon Interchange
construction.
Attachments: Proposal from Kleinfelder, Inc. dated January 20, 2016.
CLIENT MASTER SERVICES AGREEMENT
PUE16C34276
15-
This
SThis Agreement is made on: February%,,2010
Between City of Pueblo, CO with offices at 211 D. Street, Pueblo,Colorado 81003 (Client)
And Kleinfelder, Inc. with offices at 4815 List Drive, Unit 115, Colorado Springs, CO 80919-
3340 (Kleinfelder).
Recitals
A. Client wishes to appoint Kleinfelder to provide certain services (the Services, as defined below) required by
Client or Client's agreement with the Owner for one or more projects on a Work Order basis and on the terms
and conditions contained in this Agreement.
B. Kleinfelder has agreed to perform the Services on the terms and conditions contained in this Agreement.
Now it is agreed as follows:
1. CONTENTS OF AGREEMENT
1.1 The parties agree that the documents listed in 1.1(a) through (e) constitute the "Contract Documents" of this
Agreement. To establish obligations and resolve ambiguities in the Contract Documents,the following order of
precedence will prevail:
(a) first, amendments and Change Orders issued in accordance with this Agreement;
(b) second, Work Orders(Appendix A, as defined below);
(c) third, Kleinfelder's Proposal, dated January 20, 2016, which the Client acknowledges receipt and
confirms understanding of,and agreement with the contents thereof, in full(Appendix B),or Kleinfelder's
Proposals subsequently issued and referenced, attached or incorporated into Work Orders;
(d) fourth,this Agreement; and
(e) fifth, those portions of the Client's agreement with Owner dated (Prime Agreement), if and as
applicable to Kleinfelder and incorporated as provided in clause 1.4 (Appendix C).
1.2 To the extent of any inconsistency between this Agreement and any Prime Agreement, the provisions of this
Agreement will always prevail.
1.3 Any pre-printed terms and conditions on forms used by either party in the administration of this Agreement are
void and do not supplement or replace the terms and conditions of the Contract Documents of this Agreement.
1.4 Kleinfelder agrees to be bound to Client in the same way Client is bound to (Owner), to the extent the
provisions referenced at clause 1.1(e) are applicable to the Services under a given Work Order and provided
those provisions of the Prime Agreement are expressly identified and furnished to Kleinfelder prior to entering
into the Work Order.
Client Master Services Agreement(USA) July 2014
Page 2
2. APPOINTMENT AND SCOPE OF SERVICES
2.1 This Agreement anticipates the execution of various written work orders (in the form of Appendix A)which the
parties agree will specify the scope of Services to be performed (Services) and Client's project for which the
Services will be performed (Project), the location of Client's Project for providing the Services (Site), the time
period for performance, the agreed fees and additional provisions, if any, applicable to such Services (Work
Orders).
2.2 By executing this Agreement, Client does not guarantee any future work, nor does Kleinfelder commit to
performing any specific future Work Order.
3. STANDARD OF CARE
3.1 Kleinfelder will perform its Services in a manner consistent with that level of care and skill ordinarily exercised
by other members of Kleinfelder's profession practicing in the same locality, under similar conditions and at the
date the Services are provided.
3.2 Kleinfelder makes no representation, guarantee or warranty, express or implied, regarding the Services, or any
communication(oral or written), certification, report, opinion, or Instrument of Service provided pursuant to this
Agreement.
3.3 Kleinfelder will not be responsible for constant or exhaustive inspection of the work, for the means, methods,
techniques sequences or procedures of construction, or for the safety procedures employed by any party other
than its own employees,subconsultants and subcontractors.
3.4 No level of assessment can conclusively determine whether a property or its structures are completely free of
geotechnical hazards or hazardous substances(including but not limited to mold). Client represents that it has
carefully reviewed the limitations described in the Proposal.
3.5 Even with diligent observation,some defects,deficiencies,or omissions may occur. Before exercising any other
remedy for any alleged breach by Kleinfelder of this Agreement, Client will direct Kleinfelder in writing to re-
perform any defective Services within twelve(12)months after completion of the Services.
3.6 Kleinfelder will only sign certifications relating to the Services if Kleinfelder agreed in writing prior to the
commencement of the Services to provide such certifications. Such certifications are statements of professional
opinion only.
4. KLEINFELDER'S RESPONSIBILITIES
4.1 Kleinfelder will perform the Services as an independent contractor and not as an agent or employee of Client.
Nothing in this Agreement creates any special relationship or fiduciary duty.
4.2 Kleinfelder will,as reasonably directed by Client or its authorized agent:
(a) provide qualified staff to perform the Services;
(b) maintain records of Project activities and costs for no more than three years from its completion of the
Services;
(c) coordinate to the extent reasonably possible with Client's employees,contractors, consultants so as not
to impede the progress of the Project; and
(d) require its personnel to maintain a safe,clean and orderly work environment.
Client Master Services Agreement(USA) July 2014
Page 3
6. TERM AND TERMINATION
5.1 This Agreement will commence on the date of its execution, except as to any Services authorized by Client and
performed by Kleinfelder beforehand,and will continue in effect for two years or until terminated by either party
or extended for an additional two years by mutual written agreement of the parties.
5.2 Either party may terminate this Agreement or any Work Order at any time by providing not less than ten (10)
days'written notice to the other party.
{ 5.3 Notwithstanding the termination or expiry of this Agreement, the terms of this Agreement will survive and
continue to apply to all Work Orders signed by both parties prior to the Agreement's effective termination or
expiry date, and until all of the rights and obligations of both parties have been fulfilled.
5.4 Within fifteen (15) days from termination Client will pay Kleinfelder on demand for all Services rendered and
costs incurred through to the date of any termination and for all reasonable costs and expenses incurred by
Kleinfelder in effecting the termination, including, without limitation, non-cancellable commitments, fixed cost
components and other demobilization costs.
6. COMPENSATION
6.1 In consideration for undertaking the Services, the Client shall pay to Kleinfelder the sum specified in each Work
Order in payments in accordance with the terms of each Work Order and the payment provisions of this
Agreement.
6.2 Client agrees to provide any special invoicing requirements to Kleinfelder in advance of signing this Agreement,
to which additional charges may apply.
6.3 Kleinfelder reserves the right to periodically adjust its fee schedule.
6.4 Kleinfelder will generally submit its invoices to Client on a monthly basis. Client must pay all invoices within thirty
(30) days from the date of invoice; with interest at the rate of one and one-half percent (1 1/2 %) per month
payable on all outstanding payments. Interest on all outstanding payments will be charged from the initial date
of invoice.
6.5 Kleinfelder may suspend performance of Services under this Agreement until it has been paid in full for all
outstanding payments, including interest charges.
6.6 Kleinfelder will be entitled to recover from Client on demand all expenses incurred(including all legal costs and
expenses)in recovering any outstanding payments from Client.
6.7 All travel will be invoiced at cost and reimbursed by Client. All travel required under this Agreement is subject
to the terms,conditions and applicable rates set forth in the U.S. Federal Travel Regulations.
7. INSURANCE
7.1 Kleinfelder will maintain during the term of this Agreement worker's compensation, commercial general liability,
automobile liability Insurance and professional indemnity Insurance coverage.
7.2 Client will maintain during the term of this Agreement adequate insurance coverage and will require and verify
any contractors or parties it hires to have adequate insurance coverage. Client agrees that failure to comply
with this clause will invalidate any indemnify provided by Kleinfelder under clause 12.1.
Client Master Services Agreement(USA) July 2014
Page 4
8. CHANGES TO SCOPE OF SERVICES
8.1 Client or Kleinfelder may request to modify the scope of Services as set out in any Work Order,whereon both
parties agree to negotiate In good faith and execute a written Change Order. A Change Order Is an amendment
to this Agreement or to a Work Order that modifies the Services and specifies the following:
(a) a change in the terms and conditions or Services;
(b) an adjustment in the schedule for performance;and
(c) the amount of adjustment in Kleinfelder's compensation.
8.2 Kleinfelder will treat as a Change Order any written or oral Client order (including directions, instructions,
interpretations, or determinations) which request changes in the Services. Kleinfelder will give Client written
notice within a reasonable time of any resulting adjustment in the schedule and compensation. Unless Client
objects in writing within 5 business days, the proposed terms of the Change Order with the adjustment in the
schedule and price shall become a part of this Agreement.
8.3 If Client and Kleinfelder cannot agree upon an equitable adjustment in the schedule and compensation, and
Kleinfelder does not sign the Change Order, the disagreement shall be treated as a Dispute under clause 18.
9. FORCE MAJEURE
9.1 Kleinfelder will not be liable for delay or failure to perform its Services caused directly or indirectly by
circumstances beyond its control, including but not limited to, acts of God, fire, flood, war, sabotage, accident,
labor dispute, shortage, government action or inaction, changed conditions, delays resulting from actions or
inactions of Client or third parties, Site inaccessibility or inability of others to obtain material, labor, equipment,
or transportation.
9.2 Should any of the preceding circumstances occur,then the date for completion or any other milestone date shall
be adjusted for the delay in accordance with clause 8, provided Kleinfelder reports the delay to Client within a
reasonable time of discovery.
10. INSTRUMENTS OF SERVICE
10.1 All data, reports, drawings, plans, or other documents (or copies) provided to Kleinfelder by Client for the
purposes of this Agreement will, at Client's written request, be returned upon completion of the Services and
payment in full for all Services rendered. Client agrees that Kleinfelder may retain one copy of all such
documents.
10.2 Client agrees:
(a) all reports, drawings,plans,documents,software, source code,object code, boring logs,field data,field
notes,calculations,estimates,laboratory test data and other similar data,documents and work products
(or copies thereof) in any form prepared by Kleinfelder pursuant to this Agreement are instruments of
service(Instruments of Service), not products;
(b) Kleinfelder will retain exclusive ownership, copyright and title to all Instruments of Service, and Client
has no rights to incomplete or partial data;
(c) all opinions,certifications,communications(oral or written)or Instruments of Service furnished to Client
are intended for the benefit of Client for the specific purposes stated herein and therein,are not intended
to inform,guide,or otherwise influence any entities or persons other than Client in relation to the Project,
and are not intended or represented to be suited for reuse by Client or others, and;
(d) reuse without the specific prior written consent of Kleinfelder will be at the user's sole risk and without
Kleinfelder liability, and Client agrees (i) to remove Kleinfelder's and Kleinfelder's consultants' names
and seals therefrom, and (ii) to defend, indemnify and hold harmless Kleinfelder and Kleinfelder's
Client Mester Services Agreement(USA) July 2014
Page 5
contractors, consultants, affiliates, directors and employees from and against all losses, damages and
liabilities (including all legal expenses) in connection with the unauthorized use.
10.3 Any requests by third parties for reliance upon any communication(oral or written), certification, report,opinion,
or Instrument of Service provided by Kleinfelder pursuant to this Agreement will be subject to approval at
Kleinfelder's sole discretion and to additional fees, terms and conditions.
11. CLIENT'S RESPONSIBILITIES
11.1 Client agrees to provide and discuss with Kleinfelder on an ongoing basis throughout all available material,data,
and information pertaining to the Services, including, without limitation, (i)the composition, quantity,toxicity, or
potentially hazardous properties of any material known or believed to be present at any Site, (ii) any hazards
that may be present, (iii)the nature and location of underground or otherwise not readily apparent utilities, (iv)
summaries and assessments of the Site's past and present compliance status, (v) the status of any filed or
pending judicial or administrative action concerning the Site or Project, and (vi) Client records (in electronic
format where possible) for such data as benchmarks, plans, maps, and property ownership.
11.2 Client will ensure the cooperation of Client's employees, contractors and consultants with Kleinfelder.
11.3 Client acknowledges and agrees that Kleinfelder is entitled to rely upon the accuracy and completeness of any
information given by Client, its employees, contractors and consultants.
11.4 Client will provide reasonable assistance to obtain data and records concerning the Site or Project in the
possession, custody or control of third parties.
12. ALLOCATION OF RISK AND INDEMNITIES
12.1 Subject to the limitation of liability provisions of this Agreement, Kleinfelder indemnifies Client against all
liabilities, losses or damages caused by the negligence or other fault of Kleinfelder and its employees, agents,
representatives, subcontractors, and any other party for whom Kleinfelder is legally responsible (Klelnfelder
Parties), but only to the extent such liabilities, losses or damages are caused by the negligence or other fault of
the Kleinfelder Parties when compared to the negligence or other fault of all other persons and entities. If
California law applies to this Agreement,the parties also expressly agree that this indemnity provision does not
include, and in no event shall Kleinfelder be required to assume, any obligation or duty to defend any claims,
cause of action, demands,or lawsuits in connection with or arising out of this Project or the Services rendered
by Kleinfelder. This clause 12.1 is not intended to and will not in any way be limited by any insurance coverage
available to Client under any Kleinfelder insurance policy.
12.2 Client indemnifies Kleinfelder against all liabilities, losses or damages caused by the negligence or other fault of
Client and its employees,agents,representatives, subcontractors,and all other parties for whom Client is legally
responsible (Client Parties), but only to the extent such liabilities, losses or damages are caused by the
negligence or other fault of Client Parties when compared to the negligence or other fault of all other applicable
persons and entities. If California law applies to this Agreement, the parties also expressly agree that this
indemnity provision does not include, and in no event shall Client be required to assume, any obligation or duty
to defend any claims, cause of action, demands, or lawsuits in connection with or arising out of this Project or
services rendered by Client. This clause 12.2 is not intended to and will not in any way be limited by any
insurance coverage available to Kleinfelder under any Client, Owner or Project insurance policy.
12.3 Subject to any applicable statutory limitations, the indemnity obligations in this clause 12 shall survive the
expiration or termination of this Agreement.
Client Master Services Agreement(USA) July 2014
Page 6
13. LIMITATION OF LIABILITY
13.1 The maximum aggregate liability of Kleinfelder arising out of or related to this Agreement and all Work Orders
and amendments thereto, whether based in contract or tort or otherwise in law or equity, will be limited to the
greater of the compensation actually paid to Kleinfelder for the Services under all Work Orders or$50,000, and
Client hereby releases Kleinfelder from any liability above such amount. This limitation of liability includes any
losses payable to Client under clause 12.1 and will apply to any and all claims.
13.2 This limitation of liability has been agreed after Client and Kleinfelder discussed the risks and rewards associated
with the Project and the Services as well as the provision of the Services within both the obligations of this
Agreement and the associated compensation. Upon written request by Client,the parties may negotiate in good
faith and agree, by way of a written Change Order in accordance with clause 8 herein, to increase the amount of
this liability limitation or eliminate it in exchange for payment of increased compensation to Kleinfelder,
13.3 As used in this clause 13,"Kleinfelder"includes Kleinfelder,its affiliates,subconsultants and subcontractors,and
their respective partners,officers, directors, shareholders and employees. The limitation of liability established
in this clause 13 shall survive the expiration or termination of this Agreement.
14. WAIVER OF CONSEQUENTIAL DAMAGES
14.1 Neither party will be liable to the other party for any special, incidental, indirect, exemplary, punitive, penal or
consequential damages however arising incurred by either Kleinfelder or Client or for which either may be liable
to a third party.
15. NO CONTROL OF MEANS AND METHODS OF OTHERS
15.1 Client agrees:
(a) Kleinfelder will have no control over or charge of or responsibility for the construction means, methods,
techniques, sequences, or procedures, or for the safety precautions and programs of Client's
employees, or contractors or consultants engaged by Client in connection with the Project;
(b) Kleinfelder's performance of the Services does not include any job site safety obligations which may be
required by or in connection with the Project or the Services or any applicable code or regulation, other
than strictly in respect of its own employees;and
(c) Kleinfelder will not have control over or charge of the acts or omissions of any contractor or contractors'
agents,employees or subcontractors.
16. SITE ACCESS
16.1 Client agrees to:
(a) provide unimpeded and timely access to the Site, including any third party sites, if required;
(b) provide an adequate area for Kleinfelder's Site office facilities, equipment storage,and parking;
(c) furnish all construction utilities and utility releases necessary for the performance of the Services;and
(d) obtain all permits, licenses or authorizations necessary for the performance of the Services.
17. WARRANTY OF TITLE,WASTE OWNERSHIP
17.1 Kleinfelder will not take title to or be liable for any hazardous materials found at any Project Site.Any risk of loss
with respect to all materials remains with Client or the Site owner, who will be considered the generator of such
materials, execute all manifests as the generator of such materials, and be liable for the arrangement,
Client Master Services Agreement(USA) July 2014
Page 7
transportation,treatment,and/or disposal of all material.All samples remain the property of Client.Client agrees
to promptly, at its cost, remove and lawfully dispose of samples, cuttings, and hazardous materials.
18. DISPUTE RESOLUTION
18.1 If a dispute arises out of or relates this Agreement(Dispute),the parties agree to submit the Dispute to mediation
pursuant to the Construction Industry Mediation Rules of the American Arbitration Association (AAA). The
mediator will be an independent person agreed between the parties from a panel suggested by the Institute or,
failing agreement, a mediator appointed by AAA. A party shall not call for mediation of any Dispute after such
period of time as would bar the initiation of legal proceedings to litigate such Dispute under the laws of the state
in which the Project is located.
18.2 Client and Kleinfelder agree that in the event of a Dispute,they will not seek recourse against individual officers,
employees, directors,or shareholders of the other party.
18.3 A party shall not start court proceedings in relation to a Dispute until it has exhausted the procedures in this
clause, unless the party seeks injunctive or other interlocutory relief.
18.4 If the Dispute cannot be resolved through mediation,either party may file suit in an appropriate court in the state
where the Services are performed.
18.5 This clause survives termination or expiry of this Agreement.
19. MISCELLANEOUS
19.1 This Agreement is governed and construed in accordance with the laws of the state where the Services are
performed. The parties hereby submit to the jurisdiction of the courts of the state where the Services are
performed and waive any right to object to any proceedings being brought in those courts.
19.2 Waiver of any term, condition or breach of this Agreement will not operate as a subsequent waiver of the same
term, condition or breach. A waiver is not valid or binding unless made in writing.
19.3 If any provision of this Agreement is found by a duly constituted authority to be invalid, void, or unenforceable,
all remaining provisions shall continue in force.
19.4 This Agreement does not create, nor will it be construed to create, any benefit or right in any third party or any
special relationship or fiduciary duty to third parties.
19.5 This Agreement constitutes the entire understanding and agreement of the parties with respect to its subject
matter. It supersedes all earlier conduct, prior agreements and understandings between the parties in
connection with its subject matter.
19.6 Client and Kleinfelder shall abide by the requirements of 41 CFR 60-1.4(a),60-300.5(a)and 60-741.5(a). These
regulations prohibit discrimination against qualified individuals based on their status as protected veterans or
individuals with disabilities, and prohibit discrimination against all individuals based on their race,color, religion,
sex, or national origin. Moreover,these regulations require that covered prime contractors and subcontractors
take affirmative action to employ and advance in employment individuals without regard to race, color, religion,
sex, national origin, protected veteran status or disability.
Client Master Services Agreement(USA) July 2014
1
Page 8
19.7 All notices, requests or instructions hereunder must be in writing and either hand delivered to the recipient,
delivered by registered mail or express mail the addresses given in this Agreement.
19 8 This Agreement cannot be assigned by either party without the prior written approval of the other party.
Kleinfelder may subcontract performance of portions of the Services to a qualified subcontractor.
19.9 Any amendment or revision to this Agreement, including for the avoidance of any doubt, to any Work Order,
must be in writing and signed by both parties. Any oral modification or revision of this Agreement shall not operate
to modify this Agreement.
19.10 This Agreement may be executed in counterparts, including photo or electronic copies, which taken together,
shall constitute one original document.
IN WITNESS WHEREOF, Client and Kleinfelder have caused this Agreement to be executed on the date first written
above.
CLIENT:CITY OF PUEBLO KLEINFELDER:
By: GLv!►'l.r /C/ ,l '_'.."' By:
dye'
Printed Name: Ms. Naomi Hedden Printed Name: William J. Barreire, PE
Title: Purchasing Director Title: Vice President
ATTACHMENTS: Appendix A, Sample Work Order
Appendix B, Kleinfelder Proposal(as applicable)
Appendix C, Prime Agreement/Client Requirements(as applicable)
Attested by:
Cit Clerk
Client Mester Services Agreement(USA) July 2014
WORK ORDER 1
Dillion Drive/I-25 Interchange Materials Testing and Inspection Services
City of Pueblo Project No.'13-084; RFQ 13-084
Issued Pursuant to The Client Master Services Agreement PUE16C34276 effective as of February 15,2016
by and between City of Pueblo,CO (Client)and Kleinfelder, Inc. (Kleinfelder).
Client Name: City of Pueblo,CO Kleinfelder Project No: MW160549.001P/PUE1633575
Project Name: Dillon Drive Interchange Work Order Type: (Check One)
®Time-and-Materials
0 Fixed-Price
Kleinfelder Office: Pueblo, CO Subcontractor Reference No:
Kleinfelder Contact Name: Tyra Sandy—tsandv( kleinfelder.com
1. SCOPE OF WORK: as outlined in revised proposal dated January 20, 2016 for Quality
Assurance on the Dillon Drive/I-25 Interchange Project City of Pueblo Project. Project No. 13-084.
(Continue on additional page, if needed)
2. LOCATION/CLIENT FACILITY INVOLVED: Dillon Drive/I-25 Interchange Project, City of Pueblo, CO
3. PERIOD OF PERFORMANCE: FROM: February 15,2016 TO: July 1, 2016
4. AUTHORIZED FUNDING: $99,800.00
5. SPECIAL PROVISIONS:
NOTICE TO PROCEED IS GIVEN ON(DATE):
CLIENT:City of Pueblo,CO KLEINFELDER:
By: ) J?1Ci*+''' `. By: /1,.
I
Printed Name: Ms. Naomi Hedden Printed Name: illiam J. Barreire, PE
Title: Purchasing Director Title: Vice President
Attested by• Address: 4815 List Drive, Unit 115
Colorado Springs, CO 80919-3340
Cior Clerk
Client Master Services Agreement—Work Order(USA) July 2014
Client Mester Services Agreement—Work Order(USA) July 2014