HomeMy WebLinkAbout10391RESOLUTION NO. 10391
A RESOLUTION APPROVING AN AGREEMENT BETWEEN THE CITY OF PUEBLO AND HGF
ARCHITECTS, INC., FOR PROFESSIONAL SERVICES ASSOCIATED WITH THE DESIGN OF A
HANGAR BUILDING AT THE PROPOSED CORPORATE HANGAR COMPLEX AT THE PUEBLO
MEMORIAL AIRPORT
BE IT RESOLVED BY THE CITY COUNCIL OF PUEBLO, that:
SECTION 1.
An Agreement, a copy of which is attached hereto, after having been approved as to form
by the City Attorney, by and between Pueblo, a Municipal Corporation and HGF Architects, Inc., is
hereby approved.
SECTION 2.
Funds for said professional services shall be paid from Project No. ED0402.
SECTION 3.
The President of the City Council is hereby authorized to execute the said Agreement on
behalf of Pueblo, a Municipal Corporation, and the City Clerk shall affix the seal of the City thereto
and attest the same.
INTRODUCED May 9, 2005
BY Michael Occhiato
Councilperson
APPROVED:
PRES1DENT 9F CITY C IL
ATTESTED BY:
CITY CLERK
Background Paper for Proposed
RESOLUTION
PZ00':
AGENDA ITEM #
DATE: MAY 9, 2005
DEPARTMENT: PUBLIC WORKS
DIRECTOR — DANIEL E. CENTA, P.E.
TITLE
A RESOLUTION APPROVING AN AGREEMENT BETWEEN THE CITY OF
PUEBLO AND HGF ARCHITECTS, INC., FOR PROFESSIONAL SERVICES
ASSOCIATED WITH THE DESIGN OF A HANGAR BUILDING AT THE
PROPOSED CORPORATE HANGAR COMPLEX AT THE PUEBLO MEMORIAL
AIRPORT.
ISSUE
Should the City Council enter into an agreement with HGF Architects, Inc.,
for the purpose of performing architectural and engineering services for the design of a
hangar building at the proposed corporate hangar complex at the Pueblo Memorial
Airport.
RECOMMENDATION
Approval of this Resolution.
BACKGROUND
This contract will provide the architectural and engineering services necessary to design a
hangar building and associated site work.
Funds for the construction of this project have been previously approved by City Council.
This design contract will utilize a small portion of those funds and will allow the
Department of Public Works the ability to get the construction contract to bid in a timely
manner, so that the project can begin construction this year.
FINANCIAL IMPACT
The cost of this service is $51,300 and will be paid from Project No. ED0402. An
additional $23,700 is requested for contingencies, for a total of $75,000.
STANDARD FORM OF
AGREEMENT FOR PROFESSIONAL ARCHITECTURAL SERVICES
THIS AGREEMENT made and entered this 9` day of May, 2005 by and between the City of
Pueblo, a Municipal Corporation (hereinafter "Owner ") and HGF Architects, Inc., a professional
architectural firm (hereinafter "Architect ") for Architect to render certain professional architectural
and related services for Owner in connection with Project No. 05 — 028, FY 2005 PMA Corporate
Hangar Building Design, hereinafter referred to as the "Project." In consideration of the mutual
covenants hereinafter set forth, the parties agree as follows:
SECTION 1. GENERAL
1.1 Architect shall satisfactorily perform professional architectural services for all phases
of Project indicated below by mark placed in the appropriate box or boxes:
0 - Study and Report Phase
❑x - Preliminary Design Phase
❑x - Final Design Phase
❑x - Contract Documents and bidding Phase
❑x - Construction Phase
Upon completion of any phase, Architect shall not proceed with work on the next phase, if any, until
authorized in writing by Owner to proceed therewith.
Such services shall include all usual and customary professional architectural consultation and advice
and the furnishing (directly or through its professional consultants) of customary and usual
architectural services as well as geotechnical, civil, structural, mechanical and electrical engineering
services. Architect shall also provide any landscape architectural incident to their work on the
Project.
1.2 In performing the professional services, Architect shall complete the work items
described generally in Appendix A - Scope of Services and/or Request For Proposal and the items
identified in Section 2 of this Agreement which are applicable to each phase for which Architect is to
render professional services.
1.3 Professional Architectural and/or Engineering services shall be performed under the
direction and supervision of a registered Architect or Engineer in good standing and duly licensed to
practice in the State of Colorado. All reproductions of drawings produced under this Agreement
shall be the same as at least one record set which shall be furnished to Owner and which shall be
signed by and bear the seal of such registered Architect or Professional Engineer.
1.4 Surveying work included within or reasonably contemplated by this Agreement shall
be performed under the direction and supervision of a registered Professional Land Surveyor in good
standing and duly licensed to practice in the State of Colorado. All plats and surveys produced under
this Agreement shall be signed by and bear the seal of said Professional Land Surveyor.
SECTION 2. ARCHITECT SERVICES
2.1 Study and Report Phase If Architect is to provide professional services with respect
to the Project during the Study and Report Phase, Architect shall:
(a) Consult with Owner to determine his requirements for the Project and review
available data.
(b) Advise Owner as to the necessity of his providing or obtaining from others
data or services of the types described in paragraph 2.2(c), and assist Owner in obtaining any such
services.
(c) Provide special analyses of Owner's needs, planning surveys, site evaluations
and comparative studies of prospective sites and solutions.
(d) Identify and analyze requirements of governmental authorities and regulatory
agencies involved in approval or permitting any aspect of Project.
(e) Provide general economic analysis of Owner's requirements applicable to
various alternatives.
(f) Prepare a Report with appropriate exhibits indicating clearly the
considerations involved and the alternative solutions available to Owner, and setting forth Architect's
findings and recommendations with opinions of probable costs.
(g) Furnish ten (10) copies of the Report and present and review it in person with
Owner.
2.2 Preliminary Design Phase If Architect is to provide professional services with
respect to the Project during the Preliminary Design Phase, Architect shall:
(a) Consult with Owner and determine the general design concept and Project
requirements based upon information furnished by Owner as well as any study Report on the Project.
(b) Prepare and submit to Owner preliminary design documents consisting of final
design criteria, preliminary drawings, an outline of specifications, and written descriptions of all
significant features of Project.
-2-
(c) Prepare and submit to Owner a requirements checklist of any subsurface
investigation, additional data, permits, or other information and requirements which is anticipated
will be necessary for the design or construction of Project.
(d) Provide written disclosure to Owner of significant design assumptions and
design risks inherent in or presented by design alternatives, and make recommendations to Owner
based thereon.
(e) Prepare and submit to Owner a preliminary cost estimate for the Project
including construction cost, contingencies, professional compensation, consultant fees, costs of land
and rights of way, compensation for damages and finance costs, if any.
(f) Architect shall furnish ten (10) copies of each above referenced submittal
document to Owner for Owner's use, and shall review same in person with Owner.
2.3 Final Design Phase . If Architect is to provide professional services with respect to
the Project during the Final Design Phase, Architect shall:
(a) After consultation with the Owner, receipt of Owner's selection of any design
options and review of the Preliminary Design Documents, if any, prepare and submit to Owner final
Drawings showing the scope, extent and character of the work to be performed by contractors, and
Specifications describing such work and the requirement therefor. Such plans and Specifications
shall comply with all applicable building codes and requirements of regulatory agencies having any
approval authority.
(b) Make reasonable revisions to the Drawings and Specifications requested by
Owner, informing the Owner of any change in probable construction costs as a result of such
revisions.
(c) Provide technical criteria, written descriptions and design data for Owner's
use, and disclose any significant design risks inherent in or presented by design choices.
(d) Based upon Architect's best professional judgment, prepare and submit to
Owner a current detailed cost estimate for the Project including construction cost, contingencies,
professional compensation, consultant fees, land and right of way costs, damages and finance costs,
if any.
2.4 Contract Documents and Bidding Phase If Architect is to provide professional
services with respect to the Project during the Contract Documents and Bidding Phase, Architect
shall:
(a) Prepare and submit to Owner draft forms of contract agreement, general and
special conditions, bid forms invitations to bid, information for bidders, forms of warranty and
11911
including any special requirements imposed upon such contracts by any federal or other funding
source and by any regulatory agency. In preparing such draft forms, Architect shall consider and
incorporate, to the extent both advisable and feasible, owner's standard forms of agreement,
warranty, payment and performance bonds, general conditions and selected specifications.
(b) After review and comment by Owner, prepare and submit final forms of
contract agreement, general and special conditions, bid forms, invitations to bid, information for
bidders, and forms of warranty, together with any Addenda which may be required or appropriate to
correct errors, clarify Drawings or Specifications or advise of changes. Twenty-five (25) copies of
these final bid documents shall be furnished to Owner.
(c) Make recommendations to Owner concerning the need for prequalification of
equipment, vendors or bidders, and, if requested by Owner, incorporate prequalification requirements
in final bid and construction contract documents.
(d) Attend a pre -bid conference with bidders to discuss Project requirements and
receive requests for clarification, if any, to be answered by Architect in writing to all plan holders.
(e) Consult with and make recommendations to Owner concerning: acceptability
of bidders, subcontractors, suppliers, materials, equipment, suitability of proposed "or equals ",
amount of bids and any other matter involved in consideration and review of bids and bidders upon
which Owner may reasonably request Architect's advice.
2.5 Construction Phase If Architect is to provide professional services with respect to
the Project during the Construction Phase, after award by the Owner of a general contract, Architect
shall:
(a) Perform all duties and functions to be performed by Architect under the terms
of the construction contract.
(b) Visit the Project site, perform observations as to the progress and quality of
the work and advise the Owner as to same. The frequency and level of observation shall be
commensurate with the nature of the work and size of the Project, except that any specific provisions
set forth in Appendix A - Scope of Services concerning the level of observation shall determine
Architect's obligation concerning level of observation.
(c) Make determinations as to whether the work is proceeding in accordance and
compliance with the construction contract documents.
(d) Promptly advise the Owner in writing of any omissions, substitutions, defects
or deficiencies noted in the work of any contractor, subcontractor, supplier or vendor on the Project.
In
(e) Reject any work on the Project that does not conform to the contract
documents.
(f) On request of the Owner, the construction contractor or any subcontractor on
the Project, issue written interpretations as to the Drawings and Specifications and requirements of
the construction work.
(g) Review shop drawings, samples, product data and other submittals of the
contractor for conformance with the design concept of Project and compliance with the Drawings,
Specifications and all other contract documents, and indicate to Contractor and Owner with respect
thereto, any exceptions noted, or modification or resubmittals required.
(h) Review all applications of Contractor for payment and in connection with
same, issue certificates for payment to the Owner for such amounts as are properly payable under the
terms of the construction contract. Each such certificate shall constitute Architect's representation to
Owner that he has inspected the Project and that to the best of his knowledge, the work for which
payment has been sought has been completed by Contractor in accordance with the Drawings,
Specifications and other contract documents.
(i) Subject to written concurrence by Owner, promptly render a written
recommendation to Owner concerning all proposed substitutions of material and equipment.
0) Draft, for Owner's consideration, and offer recommendations upon, all
proposed change orders and contract modifications.
(k) On application for final payment by the Contractor, make a final inspection of
the Project, assembling and delivering to the Owner any written guaranties, instructions manuals, as-
built drawings, diagrams and charts required by the contract documents, and issuing a certificate of
final completion of the Project.
(1) The Architect shall if so provided in the construction contract, be the
interpreter of the construction documents and arbiter of claims and disputes thereunder. Upon
written request of the Owner or Contractor, the Architect shall promptly make written interpretations
of the contract documents and render written decisions on all claims, disputes and other matters
relating to the execution or progress of the work on the Project. The interpretations and decisions of
the Architect shall be final and binding on the Contractor and Owner, unless the Director of Public
Works of the Owner shall, within seven calendar days after receipt of the Architect's interpretation
or decision, file his written objections thereto with the Architect and Contractor.
2.6 Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely
completion and coordination of all of Architect's work, including that performed by Architect's
-5-
consultants, and including designs, Drawings, Specifications, reports and other services, irrespective
of Owner's approval or acquiescence in same. Architects shall, without additional compensation,
correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner
for all loss or damage to Owner caused by Architect's negligent act or omission; except that
Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any
requirement to obtain a certificate of review as a condition precedent to commencement of an action,
including any such requirements set forth in Section 13 -20 -602, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care
applicable to the type of architectural and engineering services provided, commensurate with the
size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's
employees in the execution of work under this Agreement, shall provide all necessary safety
equipment for said employees, and shall hold harmless and indemnify and defend Owner from any
and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related
professional services and the impact of same on the Project, the Owner has a substantial interest in
the personnel and consultants to whom Architect assigns principal responsibility for services
performed under this Agreement. Consequently, Architect represents that Architect has selected and
intends to employ or assign the key personnel and consultants identified in Appendix C -
"Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project
assignments and areas of responsibility stated therein. Within 10 days of execution of this
Agreement, Owner shall have the right to object in writing to employment on the Project of any such
key person, consultant or assignment of principal responsibility, in which case Architect employ
alternate personnel for such function or reassign suchyesponsibility to another to whom Owner has
no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any
person to whom Owner has reasonable objection.
Within 5 days of execution of this Agreement, Architect shall designate in writing a Project
representative who shall have complete authority to bind Architect, and to whom Owner should
address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization
from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order
in which Architect proposes to accomplish his work, with dates on which he will commence and
complete each major work item. The schedule shall provide for performance of the work in a timely
manner so as to not delay Owner's time table for achievement of interim tasks and final completion
of Project work, provided however, the Architect will not be responsible for delays beyond his
control.
M
(g) Before undertaking any work which Architect considers beyond or in addition
to the scope of work and services which Architect has contractually agreed to perform under the
terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the
work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or
additional work should be performed, and (iii) a reasonable estimate of the cost of such work.
Architect shall not proceed with such out of scope or additional work until authorized in writing by
Owner. The compensation for such authorized work shall be negotiated, but in the event the parties
fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for
his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule ".
SECTION 3. OWNER'S RESPONSIBILITIES
3.1 Owner shall:
(a) Designate a representative to whom all communications from Architect shall
be directed and who shall have limited administrative authority on behalf of Owner to receive and
transmit information and make decisions with respect to Project. Said representative shall not,
however, have authority to bind Owner as to matters of legislative or fiscal policy.
(b) Advise Architect of Owner's Project requirements including: objective, project
criteria, use and performance requirements, special considerations, physical limitations, financial
constraints, and required construction contract provisions and standards.
(c) Provide Architect with available information pertinent to the Project including
any previous reports, studies or data possessed by Owner which relates to design or construction of
the Project.
(d) Assist in arranging for Architect to have access to enter private and public
property as required for Architect to perform his services.
(e) Examine all studies, reports, sketches, Drawings, Specifications, proposals
and other documents presented by Architect, and render written decisions pertaining thereto within a
reasonable rime. The Owner's approval of Drawings, design, Specifications, reports and incidental
engineering work or materials furnished hereunder shall not in any way relieve the Architect of
responsibility for the professional adequacy of his work. The Owner's review, approval or
acceptance of, or payment for, any of the services shall not be construed to operate as a waiver of any
rights under this Agreement or of any cause of action arising out of the performance of this
Agreement.
(f) Upon advice of the necessity to do so from Architect, obtain required
approvals and permits for the Project. The Architect shall provide all supportive documents and
exhibits necessary for obtaining said approvals and permits.
-7-
(g) Notify Architect whenever Owner becomes aware of any substantial
development or occurrence which materially affects the scope or timing of Architect's services.
(h) Owner shall perform its obligations and render decisions within a reasonable
time under the presented circumstances. However, given the nature of Owner's internal organization
and requirements, a period of 14 days shall be presumed reasonable for any decision not involving
policy decision or significant financial impact. A period of 45 days shall be presumed reasonable for
Owner to act with respect to any matter involving policy or significant financial impact.
SECTION 4. TIME FOR PERFORMANCE
Architect's obligation to render services shall continue for such period of time as may
reasonably be required for completion of the work contemplated in Appendix A - Scope of Services
and Section 1 of this Agreement.
SECTION 5. PAYMENT
5.1 Owner will pay to Architect as full compensation for all services required to be
performed by Architect under this Agreement, except for services for additional work or work
beyond the scope of this Agreement, those maximum amounts set forth in Appendix B - "Fee
Schedule" and computed in accordance with this Section.
5.2 Architect shall submit periodic, but not more frequently than monthly, applications
for payment, aggregating to not more than the maximum amount, for actual professional services
rendered and reimbursable expenses incurred. Such applications shall be submitted with appropriate
documentation that such services have been performed and expenses incurred. Thereafter, Owner
shall pay Architect for the amount of the application within 40 days of the date of billing, provided
that sufficient documentation has been furnished, and further provided that Owner will not be
required to pay more than 90% of the maximum amount unless the Architect's services on the
Project phases for which this Agreement is applicable have been completed to Owner's satisfaction
and all required Architect submittals have been provided.
5.3 The rates of compensation for service and for reimbursable expenses to be used with
periodic and final payment applications shall be those set forth in Appendix B - "Fee Schedule."
5.4 No separate or additional payment shall be made for profit, overhead, local telephone
expenses, lodging, routine photocopying, computer time, secretarial or clerical time or similar
expenses unless otherwise provided and listed in Appendix B - "Fee Schedule."
5.5 No compensation shall be paid to Architect for services required and expenditures
incurred in correcting Architect's mistakes or negligence.
5.6 Compensation for authorized work beyond the scope of this Agreement shall be
governed by Paragraph 2.5(g).
SECTION 6. TERMINATION
6.1 The Owner reserves the right to terminate this Agreement and Architect's
performance hereunder, at any time upon written notice, either for cause or for convenience. Upon
such termination, Architect shall cease all work and stop incurring expenses, and shall promptly
deliver to the Owner all data, Drawings, Specifications, reports, estimates, calculations, summaries
and all other information, and materials as Architect may have accumulated in performing this
Agreement, together with all finished work and work in progress.
6.2 Upon termination of this Agreement for events or reasons not the fault of Architect,
Architect shall be paid at the rates specified in Appendix B - "Fee Schedule" for all services rendered
and reasonable costs incurred to date of termination; together with any reasonable costs incurred
within 10 days of termination provided such latter costs could not be avoided or were incurred in
mitigating loss or expenses to Owner or Architect. In no event shall payment to Architect upon
termination exceed the maximum compensation provided for complete performance in paragraph 5.1
and Appendix B.
6.3 In the event termination of this Agreement or Architect's services is for breach of this
Agreement by Architect, or for other fault of Architect including but not limited to any failure to
timely proceed with work, or to pay its employees and consultants, or to perform services with that
level of care and skill ordinarily exercised by professional Architects specializing in the design of
aircraft hangar facilities, or to perform work in a manner deemed unsatisfactory by Owner's Director
of Public Works, then in that event, Architect's entire right to compensation shall be limited to the
reasonable value of completed work to the Owner as determined by Owner's Director of Public
Works for services satisfactorily performed and reimbursable expenses reasonably incurred, prior to
date of termination.
6.4 Architect's professional responsibility for his completed work and services shall
survive any termination.
SECTION 7. GENERAL PROVISIONS
7.1 Ownership of Documents All designs, Drawings, Specifications, technical data, and
other documents or instruments procured or produced by the Architect in the performance of this
Agreement shall be the sole property of the Owner and the Owner is vested with all rights therein of
whatever kind and however created, whether created by common law, statutory law, or by equity.
The Architect agrees that the Owner shall have access at all reasonable times to inspect and make
copies of all notes, designs, drawings, specifications, and all other technical data pertaining to the
work to be performed under this Agreement. In the event Owner uses the designs, Drawings or
Specifications provided hereunder for another project independent from Project, without adaptation
In
by Architect, Owner shall hold harmless and indemnify Architect from all loss, claims, injury and
judgments arising from the use of such designs, Drawings or Specifications for such other project.
7.2 Insurance and Indemnity
(a) Architect agrees that he has procured and will maintain during the term of this
Agreement, such insurance as will protect him from claims under workers' compensation acts, claims
for damages because of bodily injury including personal injury, sickness or disease or death of any of
his employees or of any person other than his employees, and from claims or damages because of
injury to or destruction of property including loss of use resulting therefrom; and such insurance will
provide for coverage in such amounts as set forth in subparagraph (b).
(b) The minimum insurance coverage which Architect shall obtain and keep in
force is as follows:
(i) Workers' Compensation Insurance complying with statutory
requirements in Colorado and in any other state or states where the work is performed.
(ii) Comprehensive General and Automobile Liability Insurance with
limits not less than Four Hundred Thousand and No/ 100 Dollars ($400,000.00) per person
and occurrence for personal injury, including but not limited to death and bodily injury, Four
Hundred Thousand and No/ 100 Dollars ($400,000.00) per occurrence for property damage,
and One Million and No /100 Dollars ($1,000,000.00) for excess umbrella liability.
(iii) Professional Liability Insurance in amounts and form, and with a
deductible, acceptable to Owner.
(c) Architect agrees to hold harmless, defend and indemnify Owner from and
against any liability to third parties, arising out of negligent acts, errors or omissions of Architect, his
employees, subcontractors and consultants.
7.3 Notices Any and all notices or other communications required or permitted by this
Agreement or by law to be served on or given to either the Owner or the Engineer by the other party
shall be in writing and shall be deemed duly served and given when personally delivered to the party
to whom it is directed, or in lieu of such personal service when deposited in the United States mail,
first -class postage prepaid, addressed to the Owner, Attention: Daniel E. Centa, P.E., Department of
Public Works, 211 E. "D" Street, Pueblo, Colorado, or to the Architect at HGF Architects, Inc., 429
West 10' Street, Pueblo, Colorado 81003. Either party may change his address for the purpose of
this paragraph by giving written notice of such change to the other party in the manner provided in
this paragraph.
7.4 Entire Agreement This instrument contains the entire agreement between the Owner
and the Architect respecting the Project, and any other written or oral agreement or representation
-10-
respecting the Project or the duties of either the Owner or the Architect in relation thereto not
expressly set forth in this instrument is null and void.
7.5 Successors and Assigns This Agreement shall be binding on the parties hereto and
on their partners, heirs, executors, administrators, successors, and assigns; provided, however, that
neither this Agreement, nor any part thereof, nor any moneys due or to become due hereunder to the
Architect may be assigned by him without the written consent of the Owner.
7.6 Amendments No amendment to this Agreement shall be made nor be enforceable
unless made by written Amendment signed by an authorized representative of Architect and by
Owner's Director of Public Works.
7.7 Choice of Law This Agreement shall be governed and interpreted in accordance with
the laws of the State of Colorado.
7.8 Equal Employment Opportunity In connection with the performance of this
Agreement, Architect shall not discriminate against any employee or applicant for employment
because of race, color, religion, sex, national origin, disability or age. Architect shall endeavor to
insure that applicants are employed, and that employees are treated during employment without
regard to their race, color, religion, sex, national origin, disability or age.
7.9 Severability If any provision of this Agreement, except for Section 2.5, is determined
to be directly contrary to and prohibited by law or the requirements of any federal grant or other
Project funding source, then such provision shall be deemed void and the remainder of the
Agreement enforced. However, it is the intent of the parties that Section 2.5 of this Agreement not
be severable, and that if any provision of said section be determined to be contrary to law or the
terms of any federal grant, then this entire Agreement shall be void.
7.10 Appropriations Subject to execution of this Agreement by the Director of Finance
certifying that a balance of appropriation exists and funds are available, the amount of money
appropriated for this Agreement is equal to or in excess of the maximum compensation payable
hereunder; provided, however, that if construction is phased and subject to annual appropriation,
funds only in the amount of initial appropriation are available and Architect shall confirm availability
of funds before proceeding with work exceeding initial and subsequent annual appropriations.
SECTION 8. DISPUTES
8.1 Any dispute or disagreement between Engineer and Owner arising from or relating to
this Agreement or Architect's services or right to payment hereunder shall be determined and
decided by the Owner's Director of Public Works whose written decision shall be final and binding
unless judicial review is sought in a Colorado Court of competent jurisdiction pursuant to Rule 106,
C.R.C.P.
ONE
8.2 Pending resolution of any dispute or disagreement, or judicial review, Architect shall
proceed diligently with performance of his work under this Agreement.
SECTION 9. APPENDICES
9.1 The following Appendices are attached to and made a part of this Agreement:
Appendix A - "Scope of Services" consisting of 1 page.
Appendix B - "Fee Schedule" consisting of 1 page.
Appendix C - "Identification of Personnel, Subcontractors and Task
Responsibility."
IN WITNESS WHEREOF the parties hereto have made and executed this Agreement as of
the day and year first above written.
CITY OF PUEBLO
By - i
r sident of the C' ouncil
Attest:
City Cl c
[SEAL]
BALANCE OF APPROPRIATION EXISTS FOR THIS CONTRACT AND FUNDS ARE
AVAILABLE.
Director of Finance
APPROVED AS TO FORM:
City Attorney
-12-
ARCHITECT
APPENDIX "A"
SCOPE OF SERVICES
SCOPE OF WORK:
- Study and Report Phase
- Preliminary Design Phase
- Final Design Phase
- Contract Documents and Bidding Phase
- Construction Phase
For the design and construction of an approximate 150'x150' hangar
building.
The specific tasks included within each of the above referenced phases are
included within the City's Standard Agreement.
APPENDIX "B"
FEE SCHEDULE
FEE FOR A $1,000,000 HANGAR BUILDING:
I. STUDY AND REPORT PHASE $ 3,000
II. PRELIMINARY DESIGN PHASE $ 2,500
III. FINAL DESIGN PHASE $ 2,500
IV. CONTRACT DOCUMENT AND BIDDING PHASE $ 31,500
V. CONSTRUCTION PHASE $ 9,000
*TOTAL FEE $ 48,500
Geotechnical Engineering Fee $ 2,800
If Construction cost exceeds $1,000,000, then what is the fee, expressed as a
percentage, for that portion above $1,000,000 = 4.8 %.
Tenant finish design fee = 6.0%
'Includes all costs associated with each phase, including but not limited to incidentals such as reproduction
costs, travel expenses, telephone, administrative and secretarial fees, etc.
APPENDIX "C"
IDENTIFICATION OF PERSONNEL,
SUBCONTRACTORS, AND TASK RESPONSIBILITY
KEY PERSONNEL
James H. Gardner, Principal Architect
John M. Barnosky and or John Hurtig, Principal Architects
Mike Kohnert, Electrical Engineer
Roger Lemmon, Mechanical Engineer
Jim Valentine, Structural Engineer
One of the following Geotechnical Engineers:
CTL Thompson, Kleinfelder, Kuman, or Terracon